(L2) Terms
Terms & Conditions.
Last updated: 16 October 2026
These terms apply to your use of the BrewStack24 website and to the services we provide. By using the site or working with us, you agree to them.
Our services
BrewStack24 provides website development, app development, CRM & business automation and performance marketing. The exact scope, timeline and price of each project are agreed in a written quote or proposal.
Quotes and payments
Quotes are valid for the period stated on them. Payment milestones are listed in the proposal; work may pause if a payment is overdue.
Client responsibilities
You agree to share accurate information, content and timely feedback. Delays in providing material can move the delivery date.
Intellectual property
After full payment, you own the final deliverables created for your project. We may keep the right to show the work in our portfolio unless you ask us not to.
Website content
Project examples, figures and illustrations on this website are for general information only and are not a guarantee of specific results.
Limitation of liability
We are not responsible for losses caused by third-party platforms, hosting providers or advertising networks outside our control.
Governing law
These terms are governed by the laws of India, and any disputes fall under the courts of Indore, Madhya Pradesh.
Questions? Call 99936 63668 or visit us at 66 Goyal Vihar Colony Gate No 1, Near Khajrana Ganesh Mandir, Indore 452010.